96-08 R - Engineering Services with Morris Engineers (Water Storage Tank) -y
RESOLUTION NO . 96-08
MORRIS ENGINEERS
AGREEMENT
BETWEEN
OWNER AND ENGINEER
FOR
PROFESSIONAL SERVICES
THIS IS AN AGREEMENT made as of this q day ofki . in the year Nineteen
Hundred and Ninety-Six by and between the City of Prosper (hereinafter called OWNER) and
Timothy L. Morris, P.E. dba Morris Engineers (hereinafter called ENGINEER). OWNER
intends to construct a 500,000 gallon elevated water storage tank.(hereinafter called the project).
OWNER and ENGINEER in consideration of their mutual covenants herein agree in
respect of the performance of professional engineering services by ENGINEER and the payment
for those services by OWNER, as set forth below.
SECTION 1 - BASIC SERVICES OF ENGINEER
1.1. General
1.1.1. ENGINEER shall perform professional services as hereinafter stated which include
normal civil, structural, mechanical and electrical engineering services and normal architectural
services incidental thereto.
1.2. Preparatory Phase
ENGINEER shall:
1.2.1. Consult with OWNER to determine his requirements for the Project and review
I available data.
l .l
1.2.2. Advise OWNER as to the necessity of his providing or obtaining from others data
_ or services of the types described in Paragraph 3.3 which are not part of
ENGINEER's Basic Services, and assist OWNER in obtaining such data and
services.
1.2.3. Identify requirements of governmental authorities having jurisdiction to approve
portions of the Project designed or specified by ENGINEER with whom
consultation is to be undertaken in connection with the Project.
-1-
P.O. Box 606 5700 Highway 1417 NW Sherman, Texas 75090 903 - 786 -6021
•
1.3. Preliminary Design Phase
ENGINEER shall:
1.3.1. Prepare preliminary design criteria and outline specifications.
1.3.2. Advise OWNER if additional data or services of the types described in paragraph
3.3. are necessary and assist OWNER to obtain such data and services.
1.4. Final Design Phase
ENGINEER shall:
1.4.1. On the basis of the preliminary design, prepare final Drawings and Specifications
to show the character and scope of the work to be performed by contractor.
1.4.2. Provide technical criteria, written descriptions and design data for OWNER'S use
in filing applications for permits with or obtaining approvals of such governmental
authorities as have jurisdiction to approve the design of the Project, and assist
OWNER in consultations with appropriate authorities.
1.4.3. Furnish OWNER his opinion of typical cost based on the Drawings and
Specifications.
1.4.4. Prepare for review and approval by OWNER, its legal counsel and other advisors,
contract agreement forms, general conditions and supplementary conditions, bid
forms, invitations to bid and instructions to bidders and assist in .the preparation
of other related documents.
1.4.5. Furnish five copied of the Drawings, Specifications, and Construction Contract
Documents to the OWNER.
1.5. Bidding or Negotiating Phase
After authorization to proceed with the Bidding or Negotiating Phase, ENGINEER shall:
1.5.1. Assist OWNER to advertise for and obtain bids or negotiate proposals for each
separate prime contract for construction, materials, services; or equipment.
1.5.2. Issue Addenda as appropriate to clarify or change the Bidding Documents.
1.5.3. Consult with and advise OWNER as to the acceptability of contractors and other
persons and organizations proposed by prime contractor(s) for those portions of
the work as to which such acceptability is required by the Contract Documents.
-2-
• MORRIS ENGINEERS
Clr-
1.5.4. Consult with OWNER concerning the acceptability of substitute materials and
equipment proposed by Contractor(s) when substitution is permitted by the
Contract Documents.
1.5.5. Attend the bid opening, tabulate the bids, and assist OWNER in evaluating bids
or proposals and in assembling and awarding contracts.
1.6. Construction Phase
During the Construction Phase:
1.6.1. ENGINEER shall consult with and advise OWNER and act as OWNER'S
representative as provided by the Construction Contract. The extent and
limitations of the duties, responsibilities and authority of ENGINEER as assigned
in said Construction Contract shall not be modified except as ENGINEER may
agree in writing. All of OWNER'S instructions to Contractor(s) will be issued
through ENGINEER who will have authority to act on behalf of OWNER to the
extent provided by the Contract Documents.
1.6.2. ENGINEER shall make periodic visits to the site at intervals appropriate to the
various stages of construction as ENGINEER deems necessary to observe as an
experienced and qualified design professional the progress and quality of the
executed work and to determine in general if the work is proceeding in
accordance with the Contract Documents. ENGINEER will utilize, guide, and
direct the activities of the Resident Project Representative assigned to the
PROJECT by OWNER according to paragraph 2.2.1. and 7.3. to provide more
continuous observation of the work. Based on information obtained by such
observations, ENGINEER shall endeavor to determine if the work is proceeding
in general conformance to the Contract Documents and to keep the OWNER
informed of the progress of the work.
ENGINEER shall have no responsibility for the means, methods, techniques,
sequences or procedures of construction selected by Contractor, for safety
precautions and programs incident to the work of Contractor(s) or for any failure
of Contractor to comply with laws, rules, regulations, ordinances, codes, or
orders applicable to Contractor(s) performing their work. ENGINEER shall have
no responsibility for Contractor's failure to perform the work according to the
Contract Documents. ENGINEER may disapprove or reject Contractor's work
if ENGINEER believes the work will not produce a completed Project that
conforms to the requirements of the Contract Documents or that it will prejudice
the integrity of the design concept of the Project as reflected by the Contract
Documents.
1.6.3. ENGINEER shall issue necessary interpretations and clarifications of the Contract
-3-
MORRIS ENGINEERS
Documents. ENGINEER shall review shop drawings, samples, and other data
which Contractor is required to submit, but only for conformance with the design
concept according to the Contract Documents. ENGINEER shall evaluate
substitute materials and equipment proposed by Contractor according to the
Contract Documents. ENGINEER may, as OWNER's representative, require
special inspection or testing of the work, and shall receive and review all
certificates of inspection, testing, and approval required by laws, rules,
regulations, ordinances, codes, orders or the Contract Documents. ENGINEER
shall prepare routine Change Orders, Field Orders, and Work Change Directives.
1.6.4. ENGINEER shall act as initial interpreter of the Contract Documents and judge
of the acceptability of the work thereunder and make decisions on all claims of
OWNER and Contractor relating to the acceptability of the work or the
requirements of the Contract Documents pertaining to the execution and progress
of the work. ENGINEER shall not be liable for the results of any such
interpretations or decisions rendered in good faith.
1.6.5. Based on his on-site observations as an experienced and qualified design
professional, or information provided by the Resident Project Representative, and
on his review of Contractor's applications for payment and the accompanying data
and schedules: ENGINEER shall determine the amounts owing to Contractor and
recommend in writing payments to Contractor in such amounts; such approvals
of payment will constitute a representation to OWNER, based on such
observations and review, that the work has progressed to the point indicated.
Recommending a payment will not impose on ENGINEER responsibility to make
any examination to ascertain how or for what purpose the Contractor has used the
moneys paid on account of the Contract Price, or to determine that title to any of
the work, materials, or equipment has passed to OWNER free and clear of any
lien, claims, security interests, or encumbrances, or that there may not be other
matters at issue between OWNER and Contractor that might affect the amount
that should be paid.
1.6.6. ENGINEER shall conduct an inspection to determine if the Project is substantially
complete and a final inspection to determine if the Project has been completed in
accordance with the Contract Documents and if each Contractor has fulfilled all
of his obligations thereunder so that ENGINEER may approve, in writing, final
payment to each Contractor. ENGINEER's recommendation of any payment or
performance of any inspections does not relieve Contractor(s) of any responsibility
to fulfil the terms of the Contract Documents nor will such inspection or
recommendation place any responsibility on ENGINEER for Contractor(s) failure
to perform according to the Contract Documents.
1.6.7. ENGINEER shall not be responsible for the acts or omissions of any Contractor,
any subcontractor or any of the Contractor(s)' or subcontractors' agents or
-4-
• MORRIS ENGINEERS
employees or any other persons (except his own employees and agents) at the
Project site or otherwise performing any of the work of the Project.
1.6.8. ENGINEER shall prepare for OWNER a set of reproducible record prints of
Drawings showing those changes made during the construction process, based on
the marked-up prints, drawings and other data furnished by Contractor(s) and
Resident Project Representative to ENGINEER and which ENGINEER considers
significant.
SECTION 2 - ADDITIONAL SERVICES OF ENGINEER
2.1. General
If authorized by OWNER, ENGINEER shall furnish or obtain from others
Additional Services of the following types which are not considered normal or
customary Basic Services; these services will be paid for by OWNER as indicated
in Section 5.
2.1.1. Preparation of applications and supporting documents for governmental grants,
loans, or permits in connection with the Project; preparations or review of
environmental assessments and impact statements; and assistance in obtaining
approvals of authorities having jurisdiction over the anticipated environmental
impact of the Project.
2.1.2. Services to make measured drawings of or to investigate existing conditions or
facilities, or to verify the accuracy of drawings or other information furnished by
OWNER.
2.1.3. Services resulting from significant changes in general scope of the Project or its
design including, but not limited to, changes in size, complexity, OWNER's
schedule, or character of construction; and revising previously accepted studies,
reports, design documents or Contract Documents when such revisions are due to
causes beyond ENGINEER's control.
2.1.4. Providing renderings or models for OWNER's use.
2.1.5. Preparing documents for alternate bids requested by OWNER for work which is
not executed or documents for out-of-sequence work.
2.1.6. Investigations involving detailed consideration of operations, maintenance and
overhead expenses; providing value engineering during the course of the design,
the preparation of feasibility studies, cash flow and economic evaluations, rate
schedules and assistance in obtaining financing for the Project; detailed quantity
surveys of material, equipment and labor; and audits or inventories required in
-5-
• MORRIS ENGINEERS_
•
connection with construction performed by OWNER.
2.1.7. Furnishing the services of independent consultants for other than the normal civil,
structural, mechanical and electrical engineering and normal architectural design
incidental thereto, and providing data or services of the types described in
paragraph 3.3.
2.1.8. Assistance in connection with bid protests, rebidding or renegotiating contracts for
construction, materials, equipment or services.
2.1.9. Services in connection with Change Orders and Work Change Directives to reflect
changes requested by OWNER if the compensation for Basic Services is not
commensurate with the additional services rendered; services in making revisions
to Drawings and Specifications caused by acceptance of substitutions proposed by
Contractor; and services resulting from significant delays, changes or price
increases occurring as a direct or indirect result of material, equipment or energy
shortages.
2.1.10. Services during out-of-town travel required of ENGINEER other than visits to the
Project site as required by Section 1.
2.1.11. Providing field surveys for design purposes and engineering surveys and staking
to enable Contractor(s) to proceed with its work and any type of property surveys
or related engineering services needed for the transfer of interests in real property;
and providing other special field surveys.
2.1.12. Additional or extended services during construction made necessary by (1) work
damaged by fire or other cause during construction, (2) a significant amount of
defective or neglected work of any Contractor, (3) prolongation of the contract
time of any prime contract by more than sixty days, (4) acceleration of the work
schedule involving services beyond normal working hours, and (5) default by any
Contractor.
2.1.13. Preparation of operating, maintenance, and staffing manuals; extensive assistance
in the utilization of any equipment or system (such as initial start-up, testing,
adjusting and balancing); and training personnel for operation and maintenance.
2.1.14. Services after completion of the Construction Phase, such as inspections during
any guarantee period and reporting observed discrepancies under guarantees called
for in any contract for the Project.
2.1.15. Serving as a consultant or witness for OWNER in any litigation, arbitration,
mediation, public hearing or other legal or administrative proceeding involving the
Project.
-6-
MORRIS ENGINEERS
f '
•
2.1.16. Additional services in connection with the Project, including services normally
furnished by OWNER and services not otherwise provided for in this Agreement.
2.2. Resident Services During Construction
2.2.1. A Resident Project Representative and assistants will be furnished by OWNER
who will act as directed by ENGINEER in order to provide further protection
against defects and deficiencies in the work. OWNER and ENGINEER will
cooperate to provide mutual assistance for the accomplishment of ENGINEER's
responsibilities and those of the Resident Project Representative. OWNER and
ENGINEER shall each be responsible for their own acts or omissions and neither
may be held responsible for the acts or omissions of the other.
SECTION 3 - OWNER'S RESPONSIBILITIES
OWNER shall:
3.1. Provide full information as to his requirements for the Project.
3.2. Assist ENGINEER by placing at his disposal all available information pertinent
to the Project including previous reports and any other data relative to design and
construction of the Project.
3.3. Furnish to ENGINEER, as required by him for performance of his Basic Services,
data prepared by or services of others, such as core borings, probings and
subsurface explorations, hydrographic surveys, laboratory tests and inspections of
samples, materials and equipment; environmental assessment and impact
statements; appropriate professional interpretations of all of the foregoing;
property, boundary, easement, right-of-way, topographic and utility surveys;
property descriptions; zoning, deed, and other land use; restriction; and other
special data or consultations not covered in Paragraph 2; all of which ENGINEER
may rely upon in performing his services.
3.4. Provide, as required by the Construction Contract, engineering surveys and
staking to enable Contractor(s) to proceed with the layout of the work.
3.5. Arrange for access to and make all provisions for ENGINEER to enter upon
public and private property as required for ENGINEER to perform his services.
3.6. Examine all studies, reports, sketches, Drawings, Specifications, proposals and
other documents presented by ENGINEER, obtain advice of an attorney,
insurance counselor and other consultants as he deems appropriate for such
examination and render in writing decisions pertaining thereto within a reasonable
time so as not to delay the services of ENGINEER.
-7-
• MORRIS ENGINEERS
•
3.7. Pay all costs incident to obtaining bids or proposals from contractors.
3.8. Provide such legal, accounting, independent cost estimating and insurance
counseling services as may be required for the Project, and such auditing service
as OWNER may require to ascertain how or for what purpose any Contractor has
used the moneys paid to him under the construction contract.
3.9. Designate a person to act as OWNER's representative with respect to the work to
be performed under this Agreement. Such person shall have authority to transmit
instructions, receive information, and interpret OWNER's policies and decisions
with respect to ENGINEER's services.
3.10. Give prompt written notice to ENGINEER whenever OWNER observes or
otherwise becomes aware of any defect in the Project.
3.11. Furnish approvals and permits from all governmental authorities having
Sjurisdiction over the Project and such approvals and consents from others as may
be necessary for completion of the Project.
3.12. Furnish, or direct ENGINEER to provide, necessary Additional Services as
stipulated in Section 2 of this Agreement or other services as required.
3.13. Bear all costs incident to compliance with the requirements of this Section 3.
SECTION 4 - PERIOD OF SERVICE
4.1. The provisions of 4.2 through 4.8, inclusive, and the various rates of
compensation for ENGINEER's services provided for elsewhere in this Agreement
have been agreed to in anticipation of the orderly and continuous progress of the
Project through completion of the Construction Phase. ENGINEER's obligation
to render services hereunder will extend for a period which may reasonably be
required for the design, award of Construction Contracts, and construction of the
Project including extra work and required extensions thereto.
4.2. The services called for in the Preparatory Phase and Preliminary Design Phase
will be completed within 60 calendar days following the authorization to proceed
with that phase of services.
4.3. Upon authorization from OWNER, ENGINEER shall proceed with. the
performance of the services called for in the Final Design Phase, so as to deliver
Contract Documents for all authorized work on the Project within 90 calendar
days after the authorization to proceed with that phase of services.
4.4. ENGINEER's services under the Preparatory Phase, Preliminary Design Phase
-8-
• MORRIS ENGINEERS
4
and Final Design Phase shall each be considered complete at the earlier of(1) the
date when the submissions for that phase have been accepted by OWNER or (2)
thirty days after the date when such submissions are delivered to OWNER for
final acceptance, plus such additional time as may be considered reasonable for
obtaining approval of governmental authorities having jurisdiction over design
criteria applicable to the Project.
4.5. After acceptance by OWNER of the Contract Documents and ENGINEER's most
recent opinion of typical Project Cost and upon authorization to proceed,
ENGINEER shall proceed with performance of the services called for in the
Bidding or Negotiating Phase. This Phase shall terminate and the services to be
rendered thereunder shall be considered complete upon commencement of the
Construction Phase or upon cessation of negotiations with Contractor(s).
4.6. The Construction Phase will commence with the execution of the first prime
111/ contract to be executed for the work of the Project or any part thereof, and will
terminate upon the written recommendation by ENGINEER of final payment on
the last prime contract to be completed. Construction Phase services may be
rendered at different times in respect of separate prime contracts if the Project
involves more than one prime contract.
4.7. In the event that the work of the Project is to be performed under more than one
prime contract, OWNER and ENGINEER shall, prior to commencement of the
Final Design Phase, develop a schedule for performance of ENGINEER's
services during the Final Design, Bidding or Negotiating and Construction Phases
in order to sequence and coordinate properly such services as applicable to the
work under such separate contracts.
4.8. If OWNER has requested significant modifications or changes in the scope of the
Project, the time of performance of ENGINEER's services shall be adjusted
appropriately.
4.9. If OWNER fails to give prompt authorization to proceed with any phase of
services after completion of the immediately preceding phase, or if the
Construction Phase has not commenced within 180 calendar days after the
completion of the Final Design Phase, ENGINEER may, after giving seven days'
written notice to OWNER, suspend services under this Agreement.
4.10. If ENGINEER's services for design or during construction of the Project' are
delayed or suspended in whole or in part by OWNER for more than three months
for reasons beyond ENGINEER's control, ENGINEER shall on written demand
to OWNER (but without termination of this Agreement) be paid as provided in
Paragraph 5.3.3. for the services delayed or suspended. If such delay or
suspension extends for more than one year for reasons beyond ENGINEER's
9
• MORRIS ENGINEERS
control, or if ENGINEER for any reason is required to render services more than
one year after Substantial Completion, the various rates of compensation provided
for elsewhere in this Agreement shall be subject to renegotiation.
SECTION 5--PAYMENTS TO ENGINEER
5.1. Methods of Payment for Services and Expenses of ENGINEER.
5.1.1. Basic Services. OWNER shall pay ENGINEER for Basic Services rendered under
Section 1 on the following basis:
5.1.1.1. Lump Sum. If the work of the entire Project is awarded on the basis of one
prime contract, a lump sum fee of$44,000; if the work of the Project is awarded
on the basis of more than one prime contract, then the lump sum fee shall be
increased by 1.5% of each prime contract amount.
5.1.2. Additional Services. OWNER shall pay ENGINEER for Additional Services
rendered under Section 2 as follows:
5.1.2.1. General. For Additional Services rendered under Paragraphs 2.1.1. through
2.1.16, inclusive (except services covered by Paragraph 2.1.7. and services as
a consultant or witness under Paragraph 2.1.15), on the basis of the fee schedule
listed in paragraph 7.1.
5.1.2.2. Special Consultants. For services and reimbursable expenses of special
consultants employed by ENGINEER pursuant to Paragraph 2.1.7., the amount
billed to ENGINEER therefore times a factor of 1.05.
5.1.2.3. Serving as a Witness. For the services of the principals and employees as
consultants or witnesses in any litigation, hearing or proceeding in accordance
with Paragraph 2.1.15, at the rate of 1.2 times the fees listed in paragraph 7.1.
(but compensation for time spent in preparing to appear in any such litigation,
hearing or proceeding will be on the basis provided in Paragraph 5.1.2.1).
0 5.1.2.4. Resident Project Services. A Resident Project Representative will be furnished
under Paragraph 2.2.1. by and at the expense of OWNER.
5.1.3. Reimbursable Expenses. In addition to payments provided for in Paragraphs
5.1.1 and 5.1.2, OWNER shall pay ENGINEER the actual costs of all
reimbursable expenses incurred in connection with all Basic and Additional\
Services.
5.1.4. As used in this Paragraph 5.1, the term "reimbursable expenses" will have the
meanings assigned in Paragraph 5.3.1.
-10-
MORRIS ENGINEERS
5.2. Times of Payment.
5.2.1. ENGINEER shall submit monthly statements for Basic and Additional Services
rendered and for reimbursement expenses incurred. When compensation is on the
basis of a lump sum or percentage of construction cost the periodic statements will
be based upon ENGINEER's hourly fee schedule. OWNER shall make prompt
monthly payments in response to ENGINEER's monthly statements.
5.2.2. The OWNER shall, upon conclusion of each phase of Basic Services, pay such
additional amount, if any, as may be necessary to bring total compensation paid
on account of such phase to the following of total compensation for all phases of
Basic Services:
Phase Fee
Preliminary and Final Design $ 35,000
Bidding and Construction $ 9,000
Total $ 44,000
5.3. General
5.3.1. Reimbursable expenses mean the actual expenses incurred directly or indirectly
in connection with the Project for: transportation and subsistence incidental
thereto; obtaining bids or proposals from Contractor(s); furnishing and
maintaining field office facilities; subsistence and transportation of Resident
Project Representatives and their assistants; toll telephone calls and telegrams;
reproduction of reports, Drawings and Specifications, and similar Project-related
items in addition to those required under Section 1; insurance in addition to that
identified by Section 7.4; and, if authorized in advance by OWNER, overtime
work requiring higher than regular rates.
5.3.2. If OWNER fails to make any payment due ENGINEER for services and expenses
within sixty days after receipt of ENGINEER's bill therefore, the amounts due
0 ENGINEER shall include a charge at the rate of 1% per month from said sixtieth
day, and in addition ENGINEER may, after giving seven days' written notice to
OWNER, suspend services under this Agreement until he has been paid in full all
amounts due him for services and expenses.
5.3.3. If this Agreement is terminated by OWNER upon the completion of any phase of
the Basic Services, payments due ENGINEER for services rendered through such
phase shall constitute total payment for such services. If this Agreement is
terminated by OWNER during any phase of the Basic Services, ENGINEER will
be paid for services rendered during that phase on the basis ENGINEER's hourly
-11-
• MORRIS ENGINEERS
fee schedule times a factor of 1.25 for services rendered during that phase to date
of termination by principals and employees assigned to the Project. In the event
of any termination, ENGINEER will be paid for all unpaid Additional Services
and unpaid reimbursable expenses, plus all termination expenses. Termination
expenses mean reimbursable expenses directly attributable to termination.
SECTION 6 - GENERAL CONSIDERATIONS
6.1. Termination.
This Agreement may be terminated at the sole discretion of either party upon
thirty days' written notice.
6.2. Reuse of Documents.
All documents including Drawings and Specifications furnished by ENGINEER
pursuant to this Agreement are instruments of his services in respect of the
Project. They are not intended or represented to be suitable for reuse by OWNER
or others on extensions of the Project or on any other project. Any reuse by the
OWNER without specific written verification or adaptation by ENGINEER will
be at OWNER's sole risk and without liability or legal exposure to ENGINEER,
and OWNER shall indemnify and hold harmless ENGINEER from all claims,
damages, losses and expenses including attorneys' fees arising out of or resulting
therefrom. Any such verification or adaptation will entitle ENGINEER to further
compensation at rates to be agreed upon by OWNER and ENGINEER.
6.3. Estimates of Cost.
6.3.1. Since ENGINEER has no control over the cost of labor, materials or equipment,
or over the Contractor(s)' methods of determining prices, or over competitive
bidding or market conditions, his opinions of probable project cost, construction
cost, or typical costs provided for herein are to be made on the basis of his
experience and qualifications and represent his best judgment as a design
professional familiar with the construction industry, but ENGINEER cannot and
does not guarantee that proposals, bids, or the construction cost will not vary
from opinions of cost prepared by him. If prior to the Bidding or Negotiating
Phase OWNER wishes greater assurance as to the construction cost he shall
employ an independent cost estimator as provided in Paragraph 3.8.
6.4. Dispute Resolution.
In an effort to resolve conflicts that arise during the design or construction of the
project or following the completion of the project, the Client and the Engineer
agree that disputes between them arising out of or relating to this Agreement shall
-12-
• MORRIS ENGINEERS
. •
be submitted to nonbinding mediation. In the event a dispute between the parties
is not resolved through mediation, the prevailing party shall be awarded its costs
and expenses, including attorney's fees and other fees, necessary in the defense
thereof.
6.5. Successors and Assigns.
OWNER and ENGINEER each binds himself and his partners, successors,
executors, administrators and assigns to the other party of this Agreement and to
the partners, successors, executors, administrators and assigns of such other party,
in respect to all covenants of this Agreement; except as above, neither OWNER
nor ENGINEER shall assign, sublet or transfer his interest in this Agreement
without the written consent of the other. Nothing, herein shall be construed as
creating any personal liability on the part of any officer or agent of any public
body which may be a party hereto, nor shall it be construed as giving any rights
or benefits hereunder to anyone other than OWNER and ENGINEER.
SECTION 7 - SPECIAL PROVISIONS
OWNER and ENGINEER agree that this AGREEMENT is subject to the following special
provisions which together with the provisions hereof and the exhibits and schedules hereto
represent the entire AGREEMENT between OWNER and ENGINEER; they may only be
altered, amended or repealed by a duly executed written instrument.
7.1. Hourly Fee Schedule.
The hourly fee schedule primary project personnel are:
Engineering Services Payroll Costs:
Principal Engineer $65.00 per hour
Designer $31.00 per hour
Engineering Technician IV $28.00 per hour
Engineering Technician III $24.00 per hour
Engineering Technician II $21.00 per hour
Engineering Technician I $18.00 per hour
Engineering Administration $24.00 per hour
Surveying Services Payroll Costs:
Principal Surveyor $55.00 per hour
Surveying Assistant IV $28.00 per hour
Surveying Assistant III $24.00 per hour
Surveying Assistant II $21.00 per hour
Surveying Assistant I $18.00 per hour
Technical Typing $22.00 per hour
-13-
• MORRIS ENGINEERS
7.2. Surveying Services.
As additional services conducted pursuant to Section 2.1.11. and Section 3.3,
ENGINEER will provide surveying and mapping necessary for the design of the project
and acquisition of easements.
7.3. Resident Project Representative.
ENGINEER recommends and OWNER agrees to provide at OWNER's direct expense
a Resident Project Representative during the project construction.
7.4. ENGINEER's Insurance.
The ENGINEER shall carry Professional Liability Insurance in the amount of
$250,000.00 throughout the duration of this contract. Additionally, the ENGINEER
shall carry and keep in force during this CONTRACT, policies of insurance in the
minimum amount as set forth below.
11/ General Liability: Single Limit $100,000.00
Aggregate $300,000.00
Workers' Compensation Statutory
Automobile Liability:
Bodily Injury:
Each Person $50,000.00
Each Accident $100,000.00
Property Damage:
Each Accident $50,000.00
IN WITNESS WHEREOF the parties hereto have made and executed this AGREEMENT as of
the day and year first above written.
OWNER: ENG N E .
• City of Prosper
P. O. Box 307 Timoth L. Morris, P.E. dba orris Engineers
Prosper, Te 75078-0307 P. O. Box 606
•1 5700 Highway 1417 NW
By: Jo / 2t__..$(pd/ Sherman, Texas 75090
903-786-6021
Title:
REV. 1/23/94
MORRIS ENGINEERS
-14-
• MORRIS ENGINEERS